Resources

Client Alerts, News Articles, Blog Posts, & Multimedia

Everything you need to know about BMD and the industry.

Practical Advice: COVID-19's Impact on the Construction Industry

Client Alert

As a member of the American Bar Association, Forum on the Construction Industry, BMD participated in a COVID-19 Construction Leadership Roundtable discussion with over 450 other construction attorneys representing nearly every voice in the industry. Here is the top practical advice and key takeaways: 

  1. Safety. Safety is the overriding imperative on all construction projects. Employers should designate and empower a COVID-19 Compliance Coordinator and post on site the CDC guidelines in English and other appropriate languages. The six-foot social distancing requirement, portable handwashing, wearing gloves, prohibiting carpooling to the jobsite, and closing jobsites to the public are now considered best practices and mandatory expectations for all employers. In some states, governmental agencies are spot checking jobsites and removing individuals who are not in compliance with the CDC guidelines. The Occupational Safety and Health Administration has issued guidance for protecting employees against workplace exposures to COVID-19. Employers should also be aware of OSHA standards which may apply to workplace exposures and when a case of COVID-19 is OSHA recordable. Learn more here from BMD’s March 20, 2020 OSHA and COVID-19: Workplace Exposures, Citations and Recording Client Advisory. 
  1. Notice. Give notice early and often! After providing notice, follow up with timely reports, cost information and detailed schedule impact data. Maintain detailed records if you want to preserve any chance of recovering for delay impacts. It is not enough to generally argue that your work has been delayed by COVID-19. It must be written in a way to prevent or discourage escalation, including litigation. Be prepared to demonstrate how and when delay impacts occurred, such as utilization of a measured mile analysis to prove loss of efficiency and productivity. Helping the owner or general contractor understand the unique circumstances which caused the delay will increase your chances to cooperatively resolve the problem. 
  1. Suspension or Termination of Work. Suspension or termination of work remains an option on a case-by-case basis. Work is generally proceeding but is being impacted by CDC guidelines. Each project is unique and requires the owner’s willingness to work with prime contractors, subcontractors, suppliers, and design professionals. It has been rare for attorneys to counsel clients to stop work. There have been some suspensions of work, but often work resumes if employers and workers take appropriate CDC precautions. For example, work is proceeding at the City of Tampa, Florida airport where virtual inspections are being conducted by using affidavits, video or digital images, or in-person inspections per CDC guidelines. Some third-party inspections have been allowed and some government agencies are deferring inspections. Materials onsite are being sanitized. By contrast, due to the large number of coronavirus cases in New York and New Jersey, most private and public construction projects in those areas have been shut down. 
  1. Collaboration. Because the phrase “unchartered waters” does not begin to describe the impact that COVID-19 is having on construction projects, the best advice for prime contractors and subcontractors is to try to row in the same direction. This is no time for battles or disputes between general contractors and subcontractors. Prime contractors should ascertain the cash flow status of their subcontractors to determine whether they will be able to perform under the current revenue-starved environment. A key element for project success is that all parties need to work together to identify risks, loss of productivity, schedule impacts, supply chain issues, safety issues, etc. In fact, it has been perceived that many owners are being more forgiving on product substitutions and developing creative solutions to deal with impacts resulting from coronavirus delays – so take advantage of it while you can by being collaborative! 
  1. Liquidated Damages, Force Majeure, and Excusable Delays. How courts will interpret construction contract delay clauses, force majeure clauses and common law rights with respect to the delay impacts associated with COVID-19 remains to be seen, and it will likely be determined on a case-by-case basis. Because many courts are holding civil disputes in abeyance, immediate relief from the judicial system is unlikely. For this reason, as well as solid business judgment, it makes good sense for the parties to cooperatively engage in direct and timely discussions regarding how to proceed with construction and manage delay impacts in a mutually beneficial way. Issuance of change orders or schedule extensions may relieve some of the time and cost impacts. Prudent owners welcome timely notice because they can attempt to manage these issues and risks. Excellent communication is the key to identify problems. Deliver timely written notice and detailed substantive documentation, offer creative solutions, and try to manage the difficult circumstances together. Rather than pulling the trigger on default clauses, it is generally advisable to push across the project finish line and properly document all cost and time impacts. As we advised in the BMD Client Advisory on March 17th, the extent to which COVID-19 excuses or extends contractual obligation(s) is a fact-specific determination that will depend on the nature of the obligations and the specific language of the contract. 
  1. Project Financing. “Cash is king,” and if the availability of private and public funding is impaired, work may cease and sureties may be required to take over on payment and performance bonded projects. Conduct adequate due diligence before committing to business relationships. On an ongoing basis, be sure to request and receive adequate assurances of financial ability to pay whenever possible. 

Please feel free to reach out to Bob Hager, Justin Alaburda, David Scott, Jeff Miller, Steve Matasich or Brandon Pauley if you have any questions or comments on these issues. This is intended as general advice and should not be interpreted as legal advice. Each situation is unique and requires specific analysis of relevant contracts, facts and legal obligations.


Federal and Ohio Laws on Surprise Billing

Beginning in January 2022, Ohio providers and healthcare facilities will need to comply with both the federal No Surprises Act (“NSA”) and the state surprise billing law (HB 388), which are both designed to protect patients from unexpected medical bills.

New Year, New Laws, Old Form Documents? Exhibit A: Changes in Florida’s Real Estate Contracts

Settling into a New Year often brings renewed energy into setting and pushing new goals of building business relationships, increasing sales, and moving Letters of Intent and negotiations into final, signed agreements. It’s all too easy to grab a form document off the Internet (Google, anyone?), or to pull the last document in your files as a template for your next agreement. However, changes in the law can take effect at the beginning of the calendar year, as well as mid-year or fiscal new year, and sometimes on a random date in between. Your awareness – or lack of awareness – in changes in the law can mean the difference between keeping you and your business operating within the law or putting you at great financial and legal risk for not complying with the law. It can also result in financial and time savings or additional burden in time and costs.

Sports Betting Legal in Ohio

Ohio has made sports betting legal with Governor DeWine signing House Bill 29 into law on December 22, 2021. The Casino Control Commission will regulate sports betting in Ohio and estimates that the launch date for sports betting will be January 1, 2023.

Banking and Cannabis: Is it Legal

Marijuana is still a Schedule 1 drug and is illegal under federal law. However, I am not aware of any federal banking law or regulation, or any other federal law or regulation, which explicitly makes it illegal for banks and other financial institutions to provide their traditional services to state legal cannabis businesses.

Protections Under Federal and Ohio Law for Bona Fide Prospective Purchasers of Contaminated Property

Most industrial/commercial property developers are generally aware of the Comprehensive Environmental Response, Compensation, and Liability Act (“CERCLA”), often also referred to as “Superfund”. CERCLA, a United Stated federal law administered by the U.S. Environmental Protection Agency, was created, in part, because the U.S. Environmental Protection Agency recognized that environmental cleanup could help promote reuse or redevelopment of contaminated, potentially contaminated, and formerly contaminated properties, helping revitalize communities that may have been adversely affected by the presence of the contaminated properties. Commercial property developers should be aware that CERCLA provides for some important liability limitations for landowners that own contaminated property impacted by materials hazardous to the environment. It can also assist with landowners concerned about the potential liabilities stemming from the presence of contamination to which they have not contributed. In particular, CERCLA provides important liability limitations for landowners that qualify as (1) bona fide prospective purchasers (BFPPS), (2) contiguous property owners, or (3) innocent landowners.