Resources

Client Alerts, News Articles, Blog Posts, & Multimedia

Everything you need to know about BMD and the industry.

Journey of an International Attorney in Columbus

News Article

April 22, 2019

Posted by Shweta Chaubey, Attorney, BMD's Columbus Office

International Attorney Immigration Columbus Attorney BMD Columbus attorney Shweta Chaubey Attorney

Ohio Supreme Court Liquidated Damages Analysis: Hindsight is not 2020!

February 25, 2016In a case decided on February 24, 2016, the Ohio Supreme Court construed the enforceability of a liquidated damages provision in a public works construction contract. The Court held that when evaluating the enforceability of a liquidated damages provision in a construction contract, the court must conduct its analysis prospectively, based on the per diem amount of the liquidated damages at the time the contract is executed, and not retrospectively, based on the total amount of liquidated damages that ultimately accrue. Posted by Robert A. Hager News Article

Holy Toledo! Claims Waived Under Article 8

February 4, 2016In a February 2, 2016 decision, the Tenth District Court of Appeals in Franklin County affirmed the Court of Claims and upheld the decision to deny an electrical contractor’s claims against the University of Toledo because they were not timely asserted. Posted by Robert A. Hager