Resources

Client Alerts, News Articles, Blog Posts, & Multimedia

Everything you need to know about BMD and the industry.

CLIENT ALERT: Construction Law Update: Communication is Key! And Other Lessons Learned From A Recent Public Project Court Decision

Client Alert
December 6, 2018

In a recent decision, the Ohio Court of Claims entered a $2.2 million judgment in favor of the general trades contractor, and against a public university, in connection with an on-campus renovation project. Mid American Construction, LLC v. Univ. of Akron, Ct. of Cl. No. 2016-00685JD, 2018-Ohio-4513.

Delivered as a “multi-prime” project, the university entered into separate contracts with a construction manager and an architect, in addition to separate contracts with the general trades, plumbing, HVAC, and electrical contractors. The project was delayed and the general trades contractor and university asserted breach of contract claims against one another, each arguing that the other party’s delays and failure to perform caused the other to suffer damages.

Following trial, Judge Crawford entered a decision finding that the university’s ongoing failure to pay for work, as well as problems with coordination and schedule, not only justified the contractor’s decision to walk-off the job, but also prevented the contractor from completing its work. Thus, the university was found liable to the general trades contractor in the amount of $2.2 million, while the university’s counterclaim was denied.

The Court’s detailed thirty-three (33) page decision offers many rules and reminders for public owners, contractors, construction managers, construction claims consultants, and damages experts alike:

1.  Communication is Key. In observing the risk inherent in all construction projects, Judge Crawford aptly noted: “[p]ublic construction contracts are vast documents containing thousands of construction and procedural details, all of which amount to legal promises, and some of which would be difficult to perform. Business at the construction site is performed by skilled and unskilled workers who seek to coordinate a schedule that is often developed at a laboratory away from the work site and without communication with those individuals putting one brick on top of another.”

The point is clear. Communication delivers results. The more communicative, transparent and effective the construction team functions, the better the results. In his opinion, Judge Crawford identified thirty (30) separate reasons for delays on construction projects, the majority of which arise in the pre-construction phase and can easily be avoided with more effective communication.

What are you doing to improve communication, both internally and with other project participants? 

2.  Control What You Can Control. This decision also serves as a reminder to project owners of the importance of selecting an appropriate project delivery method, taking steps to ensure that the design is adequately developed, considering input from all stakeholders, issuing payment in a timely manner, issuing timely approvals, delivering the site to the contractor in a timely manner, hiring qualified design and construction teams, and following the contract’s written notice requirements.

Likewise, it is incumbent on contractors to identify and provide notice of unrealistic schedules, errors in contract documents, apparent design errors, constructability concerns, and questions concerning scope. Contractors are also reminded that so long as they make an honest effort to perform their contracts, and do not willfully refuse to perform, they are entitled to some portion of the contract price so long as they achieve substantial completion.

3.  The Value (or Cost) of a Good (or Bad) Construction Manager. This decision is a cautionary tale for owners and construction managers alike as the university’s liability arose, in part, from the failings of its construction manager. If the owner chooses to implement the Construction Manager At-Risk project delivery method, it must carefully select a qualified construction manager. Equally important, construction managers must deliver value to the project and their owner clients by following contract requirements such as conducting partnering sessions with contractors, providing monthly progress reports, providing look-ahead schedules, maintaining accurate and current schedule updates, timely responding to RFI’s and executing CCDs, and appropriately coordinating among contractors.

4.  Credibility Matters. If a claim arises that escalates to litigation or arbitration, judges and arbitrators tend to believe and find credibility with witnesses who are not evasive when asked tough questions, maintain a patient and frank demeanor, and provide consistent answers supported by the project documents.

5.  Battle of the Experts. Along the same lines, if a claim arises that requires expert testimony, judges and arbitrators have a tendency to agree with experts who are well-qualified, thorough, maintain an objective demeanor and deliver objective explanations, and offer testimony that is not conclusory, but is based on support and factual detail.

6.  Liquidated Damages or Compensatory Damages, But Not Both. Liquidated damages are not available under Ohio law where the party seeking to impose them is found to have contributed to an unreasonable delay. However, even in instances where a court may find a liquidated damages clause enforceable, and the party seeking damages is not in breach, it is well-settled law in Ohio that a non-breaching party may not recover both compensatory and liquidated damages.

For additional information, please feel free to contact Attorney Justin Alaburda at Brennan Manna & Diamond. He can be reached at www.jmalburda@bmdllc.com, or (330) 253-9134. 

Construction Law
Client Alert

Puerto Rico Is Open For Business

November 16, 2021Puerto Rico has the highest vaccination in the nation. More than 73% of the total population is fully vaccinated. The U.S. national average is just over 57%. The ports opened in June 2020 and San Juan held it first live concert this past summer. It is important to remember that Puerto Rico is a U.S. territory and there is no need for visas, the banking systems is almost identical to the mainland and the Island uses the U.S. postal service and U.S. dollar as its currency. There are thousands of flights from the U.S. to Puerto Rico daily and all main airlines fly to the Island.Client Alert

Ohio Medical Board Changes Telemedicine Rules

November 16, 2021A SCMS News Article by Scott Sandrock.Client Alert

The Rising Threat from Insiders – Get Your House in Order

November 16, 2021As its name implies, an ‘Insider Threat’ originates inside an organization. An ‘insider’ is any person who has or had authorized access to or knowledge of an organization’s resources, including personnel, facilities, information, equipment, networks, and systems. ‘Insider threat’ can manifest from malicious, complacent, negligent or unintentional acts that negatively affect the integrity, confidentiality, and availability of the organization, its data, personnel, or facilities. Certainly, ‘Insider Threat’ can be an activity by a bad actor employee, but can also arise from an inadvertent or unknowing action inside an organization (such as an employee who unintentionally opens a phishing email or clicks on a malicious link).Client Alert

In Cybersecurity– A Good Offense is the Best Defense

November 16, 20212021 has been a watershed moment for cybersecurity incidents as cybercrime has become a frequent headline and cyber criminals have thrived on unsuspecting and/or unprepared businesses and institutions. For example, the Solar Winds attack exposed sensitive data from top companies like Microsoft as well government agencies[1] and the Colonial Pipeline attack substantially disrupted the petroleum supply chain[2]. We have seen an almost 20% increase in data breaches and attacks since last year.Client Alert

Changes to Medicare’s Physician Fee Schedule and Outpatient Prospective Payment System

November 15, 2021Come the beginning of 2022, both the Medicare Physician Fee Schedule (“MPFS”) and Outpatient Prospective Payment System (“OPPS”) will look a little different. As a refresher, the MPFS lists the fees associated with reimbursement of services to providers at certain facilities, taking into account geography and costs. By contrast, OPPS sets reimbursement rates for hospitals and community mental health centers for outpatient services, which are determined in advance. A summary of some of the more pertinent changes to each rule will be outlined below.
Older posts
Newer posts