Resources

Client Alerts, News Articles, Blog Posts, & Multimedia

Everything you need to know about BMD and the industry.

CLIENT ALERT: Construction Law Update: Communication is Key! And Other Lessons Learned From A Recent Public Project Court Decision

Client Alert
December 6, 2018

In a recent decision, the Ohio Court of Claims entered a $2.2 million judgment in favor of the general trades contractor, and against a public university, in connection with an on-campus renovation project. Mid American Construction, LLC v. Univ. of Akron, Ct. of Cl. No. 2016-00685JD, 2018-Ohio-4513.

Delivered as a “multi-prime” project, the university entered into separate contracts with a construction manager and an architect, in addition to separate contracts with the general trades, plumbing, HVAC, and electrical contractors. The project was delayed and the general trades contractor and university asserted breach of contract claims against one another, each arguing that the other party’s delays and failure to perform caused the other to suffer damages.

Following trial, Judge Crawford entered a decision finding that the university’s ongoing failure to pay for work, as well as problems with coordination and schedule, not only justified the contractor’s decision to walk-off the job, but also prevented the contractor from completing its work. Thus, the university was found liable to the general trades contractor in the amount of $2.2 million, while the university’s counterclaim was denied.

The Court’s detailed thirty-three (33) page decision offers many rules and reminders for public owners, contractors, construction managers, construction claims consultants, and damages experts alike:

1.  Communication is Key. In observing the risk inherent in all construction projects, Judge Crawford aptly noted: “[p]ublic construction contracts are vast documents containing thousands of construction and procedural details, all of which amount to legal promises, and some of which would be difficult to perform. Business at the construction site is performed by skilled and unskilled workers who seek to coordinate a schedule that is often developed at a laboratory away from the work site and without communication with those individuals putting one brick on top of another.”

The point is clear. Communication delivers results. The more communicative, transparent and effective the construction team functions, the better the results. In his opinion, Judge Crawford identified thirty (30) separate reasons for delays on construction projects, the majority of which arise in the pre-construction phase and can easily be avoided with more effective communication.

What are you doing to improve communication, both internally and with other project participants? 

2.  Control What You Can Control. This decision also serves as a reminder to project owners of the importance of selecting an appropriate project delivery method, taking steps to ensure that the design is adequately developed, considering input from all stakeholders, issuing payment in a timely manner, issuing timely approvals, delivering the site to the contractor in a timely manner, hiring qualified design and construction teams, and following the contract’s written notice requirements.

Likewise, it is incumbent on contractors to identify and provide notice of unrealistic schedules, errors in contract documents, apparent design errors, constructability concerns, and questions concerning scope. Contractors are also reminded that so long as they make an honest effort to perform their contracts, and do not willfully refuse to perform, they are entitled to some portion of the contract price so long as they achieve substantial completion.

3.  The Value (or Cost) of a Good (or Bad) Construction Manager. This decision is a cautionary tale for owners and construction managers alike as the university’s liability arose, in part, from the failings of its construction manager. If the owner chooses to implement the Construction Manager At-Risk project delivery method, it must carefully select a qualified construction manager. Equally important, construction managers must deliver value to the project and their owner clients by following contract requirements such as conducting partnering sessions with contractors, providing monthly progress reports, providing look-ahead schedules, maintaining accurate and current schedule updates, timely responding to RFI’s and executing CCDs, and appropriately coordinating among contractors.

4.  Credibility Matters. If a claim arises that escalates to litigation or arbitration, judges and arbitrators tend to believe and find credibility with witnesses who are not evasive when asked tough questions, maintain a patient and frank demeanor, and provide consistent answers supported by the project documents.

5.  Battle of the Experts. Along the same lines, if a claim arises that requires expert testimony, judges and arbitrators have a tendency to agree with experts who are well-qualified, thorough, maintain an objective demeanor and deliver objective explanations, and offer testimony that is not conclusory, but is based on support and factual detail.

6.  Liquidated Damages or Compensatory Damages, But Not Both. Liquidated damages are not available under Ohio law where the party seeking to impose them is found to have contributed to an unreasonable delay. However, even in instances where a court may find a liquidated damages clause enforceable, and the party seeking damages is not in breach, it is well-settled law in Ohio that a non-breaching party may not recover both compensatory and liquidated damages.

For additional information, please feel free to contact Attorney Justin Alaburda at Brennan Manna & Diamond. He can be reached at www.jmalburda@bmdllc.com, or (330) 253-9134. 

Construction Law
Client Alert

Advanced Practice Providers and Telemedicine Start-Up Surge

March 8, 2022Throughout the COVID-19 pandemic, we heard a lot about “surges” that happened all over the country regarding the virus. One of the other interesting “surges” we have followed is the “surge” in new healthcare business start-ups, particularly businesses owned by advanced practice providers, such as nurse practitioners, physician assistants, certified nurse midwives, clinical nurse specialists, and certified registered nurse anesthetists (“Advanced Practice Providers” or “APPs”). One of the hottest areas in the healthcare start-up surge has been the creation of practices that are telemedicine focused.Client Alert

Ohio Department of Health Releases Updated Charge Limits for Medical Records

March 7, 2022Under Ohio law, a healthcare provider or medical records company that receives a request for a copy of a patient's medical record may charge an amount in accordance with the limits set forth in Ohio Revised Code Section 3701.741. The allowable amounts are increased or decreased annually by the average percentage of increase or decrease in the consumer price index for all urban consumers, prepared by the United States Department of Labor, Bureau of Labor Statistics, for the immediately preceding calendar year over the calendar year immediately preceding that year, as reported by the Bureau. The Director of the Ohio Department of Health makes this determination and adjusts the amounts accordingly. The list is then published, here.Client Alert

No Surprises Act Compliance (Published by NAMAS, 2/25/22)

March 7, 2022The Department of Health and Human Services published three parts to the No Surprises Act towards the end of 2021, which took effect January 1, 2022. The Act is intended to protect consumers from “balance billing,” which occurs when a patient receives a bill with a higher price than they may have anticipated because they did not have knowledge that the provider or facility was out-of-network. The purpose of this article is to note certain requirements that compliance employees will need to be aware of at their facilities, including notice and consent, good faith estimates, and public disclosures.Client Alert

No Surprises Act and You (Published in the SCMS Winter 2022 Newsletter)

March 3, 2022Legislation has been adopted by the United States Congress and the Ohio Legislature known as the “No Surprises Act” which attempts to regulate billing by professionals and facilities to patients who are not in networks with those facilities or providers at those facilities. The federal bill was triggered by some sensational news stories of patients being billed for tens of thousands of dollars for emergency care when the hospital was out of the network under the patient’s insurance plans.Client Alert

Are You Impacted by the Project Labor Agreement Executive Order?

February 28, 2022Project Labor Agreements (PLAs) are a quasi-collective bargaining agreement between employers and unions. They establish the terms and conditions of employment, including dispute resolution. They are put into place on specific projects and apply to the contractor, whether it is union or non-union. Employees hired on the project will be treated as union.
Older posts
Newer posts