Resources

Client Alerts, News Articles, Blog Posts, & Multimedia

Everything you need to know about BMD and the industry.

CLIENT ALERT: Construction Law Update: Communication is Key! And Other Lessons Learned From A Recent Public Project Court Decision

Client Alert
December 6, 2018

In a recent decision, the Ohio Court of Claims entered a $2.2 million judgment in favor of the general trades contractor, and against a public university, in connection with an on-campus renovation project. Mid American Construction, LLC v. Univ. of Akron, Ct. of Cl. No. 2016-00685JD, 2018-Ohio-4513.

Delivered as a “multi-prime” project, the university entered into separate contracts with a construction manager and an architect, in addition to separate contracts with the general trades, plumbing, HVAC, and electrical contractors. The project was delayed and the general trades contractor and university asserted breach of contract claims against one another, each arguing that the other party’s delays and failure to perform caused the other to suffer damages.

Following trial, Judge Crawford entered a decision finding that the university’s ongoing failure to pay for work, as well as problems with coordination and schedule, not only justified the contractor’s decision to walk-off the job, but also prevented the contractor from completing its work. Thus, the university was found liable to the general trades contractor in the amount of $2.2 million, while the university’s counterclaim was denied.

The Court’s detailed thirty-three (33) page decision offers many rules and reminders for public owners, contractors, construction managers, construction claims consultants, and damages experts alike:

1.  Communication is Key. In observing the risk inherent in all construction projects, Judge Crawford aptly noted: “[p]ublic construction contracts are vast documents containing thousands of construction and procedural details, all of which amount to legal promises, and some of which would be difficult to perform. Business at the construction site is performed by skilled and unskilled workers who seek to coordinate a schedule that is often developed at a laboratory away from the work site and without communication with those individuals putting one brick on top of another.”

The point is clear. Communication delivers results. The more communicative, transparent and effective the construction team functions, the better the results. In his opinion, Judge Crawford identified thirty (30) separate reasons for delays on construction projects, the majority of which arise in the pre-construction phase and can easily be avoided with more effective communication.

What are you doing to improve communication, both internally and with other project participants? 

2.  Control What You Can Control. This decision also serves as a reminder to project owners of the importance of selecting an appropriate project delivery method, taking steps to ensure that the design is adequately developed, considering input from all stakeholders, issuing payment in a timely manner, issuing timely approvals, delivering the site to the contractor in a timely manner, hiring qualified design and construction teams, and following the contract’s written notice requirements.

Likewise, it is incumbent on contractors to identify and provide notice of unrealistic schedules, errors in contract documents, apparent design errors, constructability concerns, and questions concerning scope. Contractors are also reminded that so long as they make an honest effort to perform their contracts, and do not willfully refuse to perform, they are entitled to some portion of the contract price so long as they achieve substantial completion.

3.  The Value (or Cost) of a Good (or Bad) Construction Manager. This decision is a cautionary tale for owners and construction managers alike as the university’s liability arose, in part, from the failings of its construction manager. If the owner chooses to implement the Construction Manager At-Risk project delivery method, it must carefully select a qualified construction manager. Equally important, construction managers must deliver value to the project and their owner clients by following contract requirements such as conducting partnering sessions with contractors, providing monthly progress reports, providing look-ahead schedules, maintaining accurate and current schedule updates, timely responding to RFI’s and executing CCDs, and appropriately coordinating among contractors.

4.  Credibility Matters. If a claim arises that escalates to litigation or arbitration, judges and arbitrators tend to believe and find credibility with witnesses who are not evasive when asked tough questions, maintain a patient and frank demeanor, and provide consistent answers supported by the project documents.

5.  Battle of the Experts. Along the same lines, if a claim arises that requires expert testimony, judges and arbitrators have a tendency to agree with experts who are well-qualified, thorough, maintain an objective demeanor and deliver objective explanations, and offer testimony that is not conclusory, but is based on support and factual detail.

6.  Liquidated Damages or Compensatory Damages, But Not Both. Liquidated damages are not available under Ohio law where the party seeking to impose them is found to have contributed to an unreasonable delay. However, even in instances where a court may find a liquidated damages clause enforceable, and the party seeking damages is not in breach, it is well-settled law in Ohio that a non-breaching party may not recover both compensatory and liquidated damages.

For additional information, please feel free to contact Attorney Justin Alaburda at Brennan Manna & Diamond. He can be reached at www.jmalburda@bmdllc.com, or (330) 253-9134. 

Construction Law
Client Alert

Laboratory Specimen Collection Arrangements with Contract Hospitals - OIG Advisory Opinion 22-09

May 3, 2022On April 28, 2022, the Department of Health and Human Services, Office of Inspector General (“OIG”) published an Advisory Opinion[1] in which it evaluated a proposed arrangement where a network of clinical laboratories (the “Requestor”) would compensate hospitals (each a “Contract Hospital”) for specimen collection, processing, and handling services (“Collection Services”) for laboratory tests furnished by the Requestor (the “Proposed Arrangement”). The OIG concluded that the Proposed Arrangement would generate prohibited remuneration under the federal Anti-Kickback Statute (“AKS”) if the requisite intent were present. This is due to both the possibility that the proposed per-patient-encounter fee would be used to induce or reward referrals to Requestor and the associated risk of improperly steering patients to Requestor.Client Alert

Property Owner Protection from Tax Valuation Challenges

April 29, 2022New legislation provides significant new protections for commercial property owners against challenges to valuation primarily by local school boards and prohibiting side agreements to avoid tax valuation changes. The Ohio Legislature has approved House Bill 126 which will go into effect July 2022 but will effectively apply to the 2023 tax valuation year.Client Alert

No Surprises Act Update: The IDR Portal is Open

April 25, 2022The No Surprises Act (“NSA”) became effective January 1, 2022, and has been the subject of lawsuits and criticisms since its inception. The goals of the No Surprises Act are to shield patients from surprise medical bills, provide to uninsured and self-pay patients good faith estimates of charges, and create a process to resolve payment disputes over surprise bills, which arise most typically in emergency care settings. We have written about Part I and Part II of the NSA previously. This update concerns the Independent Dispute Resolution (“IDR”) procedure created by Part II but applicable to claims covered by Part I. The Centers for Medicare & Medicaid Services (“CMS”) finally opened the Portal for providers to submit disputes to the IDR process following some updated guidance regarding the arbitration process itself.Client Alert

Updated FAQs for the No Surprises Act - Good Faith Estimates

April 7, 2022The No Surprises Act (“NSA”) became effective January 1, 2022. Meant to protect consumers from surprise medical bills, the new law is good for consumers, but vexatious for health care providers and facilities. One particular source of frustration is the operationalization of the Good Faith Estimate (“GFE”) requirement, governed by Part II of the regulations that implement the NSA. The GFE requirements apply broadly to all healthcare providers and facilities that practice within the scope of their state-issued license.Client Alert

IMPORTANT PRF UPDATE! HRSA Allows Providers the Opportunity to Correct Missed Period 1 Reporting

April 7, 2022Late Wednesday, April 6, HRSA announced that it was going to allow providers with extenuating circumstances that prevented them from preventing a completed Period 1 Report to submit a Request to Report Late Due to Extenuating Circumstances.
Older posts
Newer posts